1. Definitions
   • “Acknowledgment Document” means the document signed by the Customer in conjunction with these Terms and Conditions of Trade and applicable if the Contractor elects, whereby the Customer acknowledges the extent and effect of the provision of security the Customer provides to the Contractor in consideration of the provision of Materials or Works.
   • “Confidential Information” means information of a confidential nature whether oral, written or in electronic form including, but not limited to, this Contract, either party’s intellectual property, operational information, know-how, trade secrets, financial and commercial affairs, contracts, client information (including but not limited to, “Personal Information” such as: name, address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history) and pricing details.
   • “Contract” means the terms and conditions contained herein, together with any quotation, order, invoice or other document or amendments expressed to be supplemental to this Contract.
   • “Contractor” means Stay Connected Plumbing Pty Ltd, its successors and assigns or any person acting on behalf of and with the authority of Stay Connected Plumbing Pty Ltd.
   • “Cookies” means small files which are stored on a user’s computer.  They are designed to hold a modest amount of data (including Personal Information) specific to a particular client and website and can be accessed either by the web server or the client’s computer. If the Customer does not wish to allow Cookies to operate in the background when ordering from the website, then the Customer shall have the right to enable / disable the Cookies first by selecting the option to enable / disable provided on the website, prior to making enquiries via the website.
   • “Customer” means the person/s, entities or any person acting on behalf of and with the authority of the Customer requesting the Contractor to provide the Works as specified in any proposal, quotation, order, invoice or other documentation, and:
     • if there is more than one Customer, is a reference to each Customer jointly and severally; and
     • if the Customer is a partnership, it shall bind each partner jointly and severally; and
     • if the Customer is a part of a Trust, shall be bound in their capacity as a trustee; and
     • includes the Customer’s executors, administrators, successors and permitted assigns.
   • “GST” means Goods and Services Tax as defined within the “A New Tax System (Goods and Services Tax) Act 1999” (Cth).
   • “Intended Use” means an associated building product and the use thereof, for which the product is intended to be, or is reasonably likely to be, associated with the Works.
   • “Non-Conforming Building Product” means associated building products that are regarded as Non-Conforming for an Intended Use if, when associated with the Works:
     • the product is not, or will not be, safe; or
     • does not, or will not, comply with the relevant regulatory provisions; or
     • the product does not perform, or is not capable of performing, for the use to the standard it is represented to conform by or for a person in the chain of responsibility for the product.
   • “Price” means the Price payable (plus any GST where applicable) for the Works as agreed between the Contractor and the Customer in accordance with clause 6
   • “Works” means all Works (including consultation, manufacturing and/or installation services) or Materials supplied by the Contractor to the Customer at the Customer’s request from time to time (where the context so permits the terms ‘Works’ or ‘Materials’ shall be interchangeable for the other).
   • “Worksite” means the address nominated by the Customer to which the Materials/Works are to be supplied by the Contractor.

2. Acceptance
   • The parties acknowledge and agree that:
     • they have read and understood the terms and conditions contained in this Contract; and
     • the parties are taken to have exclusively accepted and are immediately bound, jointly and severally, by these terms and conditions if the Customer places an order for or accepts delivery of the Works.
   • In the event of any inconsistency between the terms and conditions of this Contract and any other prior document or schedule that the parties have entered into, the terms of this Contract shall prevail.
   • Any amendment to the terms and conditions contained in this Contract may only be amended in writing by the consent of both parties.
   • The Customer acknowledges and accepts that the supply ofWorks on credit shall not take effect until the Customer has completed a credit application with the Contractor and it has been approved with a credit limit established for the account.In the event that the supply of Works requested exceeds the Customer’s credit limit and/or the account exceeds the payment terms, the Contractor reserves the right to refuse delivery.
   • Where the Customer is a tenant (and therefore not the owner of the land and premises where Works are to be carried out) then the Customer warrants that they have obtained the full consent of the owner for the Contractor to carry out the Works on the owner’s land and premises. The Customer acknowledges and agrees that they shall be personally liable for full payment of the Price for the Works provided under this Contract and to indemnify the Contractor against any claim made by the owner of the premises (howsoever arising) in relation to the provision of the Works by the Contractor, except where such claim has arisen because of the negligence of the Contractor when undertaking the Works. Furthermore, the Customer agrees that they shall, upon request from the Contractor, provide evidence that:
     • they are the owner of the land and premises upon which the Works are be undertaken; or
     • where they are a tenant, that they have the consent of the owner for the Works to be carried out on the land and premises.
   • In the event that the Contractor is required to provide the Works urgently, that may require the Contractor’s staff to work outside normal business hours (including, but not limited to, working through lunch breaks, weekends and/or Public Holidays) then the Contractor reserves the right to charge the Customer additional labour costs (penalty rates will apply at time and a half normal rates), unless otherwise agreed between the Contractor and the Customer.
   • If the Contractor has been requested by the Customer to diagnose a fault that requires investigation, disassembly and/or testing, all costs involved will be charged to the Customer irrespective of whether or not the repair goes ahead.
   • Electronic signatures shall be deemed to be accepted by either party providing that the parties have complied with Section 9 of the Electronic Transactions Act 2000 or any other applicable provisions of that Act or any Regulations referred to in that Act.
3. Authorised Representatives
   • The Customer acknowledges and accepts that the Contractor shall (for the duration of the Works) liaise directly with one (1) authorised representative, and that once introduced as such to the Contractor, that person shall have the full authority of the Customer to order any Materials, Works and/or to request any variation thereto on the Customer’s behalf. The Customer accepts that they will be solely liable to the Contractor for all additional costs incurred by the Contractor (including the Contractor’s profit margin) in providing any Materials, Works or variation/s requested thereto by the Customer duly authorised representative.

4. Errors and Omissions
   • The Customer acknowledges and accepts that the Contractor shall, without prejudice, accept no liability in respect of any alleged or actual error(s) and/or omission(s):
     • resulting from an inadvertent mistake made by the Contractor in the formation and/or administration of this Contract; and/or
     • contained in/omitted from any literature (hard copy and/or electronic) supplied by the Contractor in respect of the Works.
   • In circumstances where the Customer is required to place an order for Materials, in writing, or otherwise as permitted by these terms and conditions, the Customer is responsible for supplying correct order information such as, without limitation, measurements and quantity, when placing an order for Materials (whether they are made to order Materials or not) (“Customer Error“). The Customer must pay for all Materials it orders from the Contractor notwithstanding that such Materials suffer from a Customer Error and notwithstanding that the Customer has not taken or refuses to take delivery of such Materials.The Contractor is entitled to, at its absolute discretion to waive its right under this sub-clause in relation to Customer Errors.

5. Change in Control
   • The Customer shall give the Contractor not less than fourteen (14) days prior written notice of any proposed change of ownership of the Customer and/or any other change in the Customer’s details (including but not limited to, changes in the Customer’s name, address, contact phone or fax number/s, change of trustees,or business practice). The Customer shall be liable for any loss incurred by the Contractoras a result of the Customer’s failure to comply with this clause.

6. Price and Payment
   • At the Contractor’s sole discretion, the Price shall be either:
     • as indicated on invoices provided by the Contractor to the Customer in respect of Works performedor upon placement if an order for the Materials; or
     • the Price as at the date of delivery of the Works according to the Contractor’s current price list, as previously disclosed to the Customer upon the Customer’s placement of an order for Materials; or
     • the Contractor’s quoted Price (subject to clause 2) which shall be binding upon the Contractor provided that the Customer shall accept the Contractor’s quotation in writing within thirty (30) days.
   • The Contractor reserves the right to change the Price:
     • if a variation to the Materials which are to be supplied is requested; or
     • if a variation to the Works originally scheduled (including any applicable plans or specifications) is requested; or
     • where additional Works are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, poor weather conditions, limitations to theWorksite access and/or crawl spaces,obscured Worksite defects not visible at the time of inspection (including, but not limited to, existing leaks or moisture behind walls etc), prerequisite work by a third party not being completed, inaccurate measurements, plans or specifications supplied by the Customer, availability of Materials,hard rock or other barriers below the surface,iron reinforcing rods in concrete, or hidden pipes and wiring in walls, etc.) which are only discovered on commencement of the Works; or
     • as a result offluctuations in currency exchange rates or increases to the Contractor in the cost of taxes, levies, labour or Materials; or
     • in the event of increases in the Contractor’s costs due to changes in statutory, government, or local body charges, taxes, levies, etc. with respect to the Works, or due to relevant industry awards (e.g. Worksite allowance and severance pay), which are outside the Contractor’s control.
   • Variations will be charged for on the basis of the Contractor’s quotation, and will be detailed in writing, and shown as variations on the Contractor’s invoice. The Customer shall be required to respond to any variation submitted by the Contractor within ten (10) days. Failure to do so will entitle the Contractor to add the cost of the variation to the Price. Payment for all variations must be made in full at the time of their completion.
   • At the Contractor’s sole discretion, a reasonable non-refundable deposit may be required upon placement of an order for Materials, in accordance with any quotation provided by the Contractor or as notified to the Customer prior to the placement of an order for Materials.
   • Time for payment for the Works being of the essence,the Price will be payable by the Customer on the date/s determined by the Contractor, which may be:
     • on delivery of Materials; or
     • on completion of the Works; or
     • the date specified on any invoice or other form as being the date for payment; or
     • failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Customer by the Contractor.
   • Payment may be made by electronic/on-line banking, credit card (a surcharge may apply per transaction), or by any other method as agreed to between the Customer and the Contractor.
   • The Contractor may in its discretion allocate any payment received from the Customer towards any invoice that the Contractor determines and may do so at the time of receipt or at any time afterwards. On any default by the Customer the Contractor may re-allocate any payments previously received and allocated. In the absence of any payment allocation by the Contractor, payment will be deemed to be allocated in such manner as preserves the maximum value of the Contractor’s Purchase Money Security Interest (as defined in the PPSA) in the Materials.
   • The Customer shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Customer by the Contractor nor to withhold payment of any invoice because part of that invoice is in dispute. Once in receipt of an invoice for payment, if any part of the invoice is in dispute, then the Customer must notify the Contractor in writing within three (3) business days, the invoice shall remain due and payable for the full amount, until such time as the Contractor investigates the disputed claim, no credit shall be passed for refund until the review is completed. Failure to make payment may result in the Contractor placing the Customer’s account into default and subject to default interest in accordance with clause 1.
   • Unless otherwise stated the Price does not include GST. In addition to the Price, the Customer must pay to the Contractor an amount equal to any GST the Contractor must pay for any supply by the Contractor under this or any other contract for the sale of the Materials. The Customer must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Customer pays the Price. In addition, the Customer must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.

7. Provisionof the Works
   • Subject to clause 2 it is the Contractor’s responsibility to ensure that the Works start as soon as it is reasonably possible.
   • The Works’ commencement date will be put back and/or the completion date extended by whatever time is reasonable in the event that the Contractor claims an extension of time (by giving the Customer written notice) where completion is delayed by an event beyond the Contractor’s control, including but not limited to any failure by the Customer to:
     • make a selection; or
     • have the Worksite ready for the Works; or
     • notify the Contractor that the Worksite is ready.
   • Any time specified by the Contractor for delivery of the Works is an estimate only and the Contractor will not be liable for any loss or damage incurred by the Customeras a result of delivery being late. However, both parties agree that they shall make every endeavour to enable the Works to be supplied at the time and place as was arranged between both parties. In the event that the Contractor is unable to supply the Works as agreed solely due to any action or inaction of the Customer, then the Contractor shall be entitled to charge a reasonable fee for re-supplying the Works at a later time and date, and/or for storage of the Materials.

8. Risk
   • If the Contractor retains ownership of the Materials under clause 12then:
     • where the Contractor is supplying Materials only, all risk for the Materials shall immediately pass to the Customer on delivery and the Customer must insure the Materials on or before delivery. The cost of delivery will be payable by the Customer in accordance with the quotation provided by the Contractor to the Customer, or as otherwise notified to the Customer prior to the placement of an order for the Materials. Delivery of the Materials shall be deemed to have taken place immediately at the time that the Materials are delivered by the Contractor or the Contractor’s nominated carrier to the Customer’s nominated delivery address (even if the Customer is not present at the address); and
     • where the Contractor is to both supply and install Materials then the Contractor shall maintain a contract works insurance policy until the Works are completed. Upon completion of the Works all risk for the Works shall immediately pass to the Customer.
   • Notwithstanding the provisions of clause 1 if the Customer specifically requests the Contractor to leave Materials outside the Contractor’s premises for collection or to deliver the Materials to an unattended location then such materials shall always be left at sole risk of the Customer and it shall be the Customer’s responsibility to ensure the Materials are insured adequately or at all. In the event that such Materials are lost, damaged or destroyed then replacement of the Materials shall be at the Customer’s expense.
   • Any advice, recommendation, information, assistance or service provided by the Contractor in relation to the Materials or Works supplied is given in good faith to the Customer, or the Customer’s agent and is based on the Contractor’s own knowledge and experience and shall be accepted without liability on the part of the Contractor. Where such advice or recommendations are not acted upon then the Contractor shall require the Customer or their agent to authorise commencement of the Works in writing.The Contractor shall not be liable in any way whatsoever for any damages or losses that occur after any subsequent commencement of the Works.
   • The Contractor shall be entitled to rely on the accuracy of any plans, specifications and other information provided by the Customer. The Customer acknowledges and agrees that in the event that any of this information provided by the Customer is inaccurate, the Contractor accepts no responsibility for any loss, damages, or costs however resulting from these inaccurate plans, specifications or other information.
   • The Customer warrants that any structures to which the Materials are to be affixed are able to withstand the installation thereof and that any plumbing connections (including, but not limited to, pipes, couplings and valves) are of suitable capacity to handle the Materials once installed. If for any reason (including the discovery of asbestos, defective or unsafe plumbing or latent or unfavourable soil conditions such as liquefaction residue or risk) that the Contractor, or the Contractor’s employees, reasonably form the opinion that the Customer’s premises is not safe for the Works to proceed then the Contractor shall be entitled to delay the provision of the Works (in accordance with the provisions of clause 2 above) until the Contractor is satisfied that it is safe for the installation to proceed.
   • The installation of some appliances can cause water hammer or damage to existing pipe work.The Customer agrees to indemnify the Contractor against any such loss, damage or claim that may arise if the existing pipe work is unable to accommodate the installation of the Materials.
   • The Customer acknowledges and accepts that:
     • choked drains generally indicate pipelines are not fully efficient (i.e. breakages, cracks, negative fall or tree root entry); the drain line cannot be repaired or rectified just by clearing it on its own.Blockages also occur due to disposal of sanitary hygiene products and foreign objects in sewer lines.Once cleared, the Contractor cannot give any guarantee against reoccurrence or further damage. In the event that the Customer requests the Contractor to use drain/pipe unblocking equipment (including but not limited to, CCTV camera or an electric eel), and the Contractor does not recommend the use of such equipment due to the risk of the equipment becoming lodged or stuck, the Contractor may require the Customer or their agent to authorise commencement of the Works in writing. If the drain/pipe unblocking equipment subsequently becomes lodged or stuck, the Customer shall be responsible for the cost of repair, replacement and/or retrieval of said equipment;
     • where the Contractor has performed temporary repairs that the Contractor:
       • offers no guarantee against the reoccurrence of the initial fault, or any further damage caused; and
       • will immediately advise the Customer of the fault and shall provide the Customer with an estimate for the full repair required.
     • the Contractor is only responsible for components that are replaced by the Contractor and does not at any stage accept any liability in respect of previous goods and/or services supplied by any other third party that subsequently fail and found to be the source of the failure;
     • under no circumstances, will the Contractor handle removal of asbestos product. In the event asbestos (or other hazardous material) is discovered on the Worksite:
       • the Contractor shall suspend the Works;
       • the Customer shall be fully responsible for the resolution of any resulting problems; and
       • any additional cost incurred by the Contractor shall be added to the Price under clause 2.
     • Materials supplied may:
       • fade or change colour over time;
       • expand, contract or distort as a result of exposure to heat, cold, weather;
       • mark or stain if exposed to certain substances;
       • be damaged or disfigured by impact or scratching; and
       • create undesirable smells caused by a system as a result of its normal operation.
     • The Contractor is not insured to remove furniture or fittings and will not do so, nor is the Contractor licensed to move electrical appliances.

9. Worksite Access and Condition
   • The Contractor is not responsible for the removal of rubbish from or clean-up of the building/construction Worksite/s. All rubbish generated by the Contractor will be placed in a designated area appointed by the Customer but the responsibility of removal of same is the Customer or the Customer’s agent, unless otherwise agreed.
   • It is the intention of the Contractor and agreed by the Customer that:
     • the Customer shall ensure that the Contractor has clear and free access to the Worksite at all times to enable them to undertake the Works (including carrying out Worksite inspections, gain signatures for required documents, and for the delivery and installation of the Materials). The Contractor shall not be liable for any loss or damage to the Worksite (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of the Contractor; and
     • it is the Customer’s responsibility to provide the Contractor, while at the Worksite, with adequate access to available amenities as may be required.
   • Where the Contractor requires that Materials, tools etc. required for the Works be stored at the Worksite, the Customer shall supply the Contractor a safe area for storage and shall take all reasonable efforts to protect all items from destruction, theft or damage. In the event that any of the stored items are destroyed, stolen or damaged, then the cost of repair or replacement shall be the Customer’s responsibility.
   • The Customer agrees to be present at the Worksite when and as reasonably requested by the Contractor and its employees, contractors and/or agents.
   • Worksite Inductions
     • in the event the Customer requires an employee or sub-contractor of the Contractor to undertake a Worksite induction during working hours, the Customer will be liable to pay the hourly charges for that period. If any inductionneeds to be undertaken prior to the commencement date then the Customer shall be liable to pay the Contractor’s standard (and/or overtime, if applicable) hourly labour rate; or
     • where the Contractor is in control of the Worksite, the Customer and/or the Customers third party contractors must initially carry out the Contractor’s Health & Safety induction course before access to the Worksite will be granted. Inspection of the Worksite during the course of the Works will be by appointment only and unless otherwise agreed, in such an event the Customer and/or third party acting on behalf of the Customer must at all times be accompanied by the Contractor.

10. Underground Locations
    • Prior to the Contractor commencing the Works the Customer must advise the Contractor of the precise location of all underground services on the Worksite and clearly mark the same. The underground mains and services the Customer must identify include, but are not limited to, electrical services, gas services, sewer services, pumping services, sewer connections, sewer sludge mains, water mains, irrigation pipes, telephone cables, fibre optic cables, oil pumping mains, and any other services that may be on the Worksite.
    • Whilst the Contractor will take all care to avoid damage to any underground services the Customer agrees to indemnify the Contractor in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified as per clause 1

11. Compliance with Laws
    • The Customer and the Contractor shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the Works, including any work health and safety (WHS) laws relating to building/construction sites and any other relevant safety standards or legislation.
    • The Customer shall obtain (at the expense of the Customer) all licenses and approvals that may be required for the Works.
    • Both parties acknowledge and agree:
      • to comply with the National Construction Code of Australia (NCC) and the Building Products (Safety) Act 2017, in respect of all workmanship and building products to be supplied during the course of the Works; and
      • that Works will be provided in accordance with any current relevant Australian/New Zealand Standards applicable.
    • Where the Customerhas supplied products for the Contractor to complete the Works, the Customeracknowledges that it accepts responsibility for the suitability of purpose and use for their products and the Intended Use and any faults inherent in those products. However, if in the Contractor’s opinion, it is believed that the materials supplied are Non-Conforming products as per state regulations, then the Contractor shall be entitled, without prejudice, to halt the Works until the appropriate conforming materials are sourced and all costs associated with such a change to the plans will be invoiced in accordance with clause 2.
    • Prior to commencement of any Works the Contractor shall carry a routine soundness test of the Worksite to ensure there are not any gas leaks in the existing pipework. In the event of such a discovery the Contractor where necessary will have the gas supply capped-off until the fault is found and repaired at the Customer’s expense.
    • The Customer acknowledges and accepts that in instances where the gas supply is turned off at the meter or bottles by the Contractor in order to carry out the soundness test that parts within a gas appliance may fail due to not being turned off and serviced for a long period of time including, thermocouples, blocked pilot tubes, and SIT valves on pilot assemblies. Any costs associated with such an event shall be borne by the Customer.
    • The Customer warrants that any existing plumbing, gasfitting and/or associated services in or upon the Worksite that is subject to the Materials and/or Works are in compliance with regulations. The Contractor reserves the right to halt all Works (in accordance with the provisions of clause 2 above) if in their opinion the Worksite is unsafe and/or the current positioning of the unit is illegal due to not meeting the required clearances then the Customer will be informed of this and will be given a revised quotation or estimate to install the new appliance in a safe and legal position.  Should the Customer not wish to proceed the Contractor will charge a standard fee for the time spent on Worksite based on the Contractor’s quotation.

12. Title
    • The Contractor and the Customer agree that ownership of the Materials shall not pass until:
      • the Customer has paid the Contractor all amounts owing to the Contractor; and
      • the Customer has met all of its other obligations to the Contractor.
    • Receipt by the Contractor of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.
    • It is further agreed that until ownership of the Materials passes to the Customer in accordance with clause 1:
      • the Customer is only a bailee of the Materials and unless the Materials have become fixtures must return the Materials to the Contractoron request;
      • the Customer holds the benefit of the Customer’s insurance of the Materials on trust for the Contractor and must pay to the Contractor the proceeds of any insurance in the event of the Materials being lost, damaged or destroyed;
      • the production of these terms and conditions by the Contractorshall be sufficient evidence of the Contractor’s rights to receive the insurance proceeds direct from the insurer without the need for any person dealing with the Contractor to make further enquiries;
      • the Customer must not sell, dispose, or otherwise part with possession of the Materials other than in the ordinary course of business and for market value. If the Customer sells, disposes or parts with possession of the Materials then the Customer must hold the proceeds of any such act on trust for the Contractor and must pay or deliver the proceeds to the Contractor on demand;
      • the Customer should not convert or process the Materials or intermix them with other goods but if the Customer does so then the Customer holds the resulting product on trust for the benefit of the Contractor and must sell, dispose of or return the resulting product to the Contractor as it so directs;
      • unless the Materials have become fixtures the Customer irrevocably authorises the Contractor to enter any premises where the Contractor believes the Materials are kept and recover possession of the Materials;
      • the Contractor may recover possession of any Materials in transit whether or not delivery has occurred;
      • the Customer shall not charge or grant an encumbrance over the Materials nor grant nor otherwise give away any interest in the Materials while they remain the property of the Contractor;
      • the Contractor may commence proceedings to recover the Price of the Materials sold notwithstanding that ownership of the Materials has not passed to the Customer.

13. Personal Property Securities Act 2009 (“PPSA”)
    • In this clause financing statement, financing change statement, security agreement, and security interest has the meaning given to it by the PPS
    • Upon assenting to these terms and conditions in writing the Customer acknowledges and agrees that these terms and conditions constitute a security agreement for the purposes of the PPSA and creates a security interest in all Materials and/or collateral (account) – being a monetary obligation of the Customer to the Contractor for Works – that have previously been supplied and that will be supplied in the future by the Contractor to the Customer.
    • The Customer undertakes to:
      • promptly sign any further documents and/or provide any further information (such information to be complete, accurate and up-to-date in all respects) which the Contractor may reasonably require to:
        • register a financing statement or financing change statement in relation to a security interest on the Personal Property Securities Register;
        • register any other document required to be registered by the PPSA; or
        • correct a defect in a statement referred to in clause 3(a)(i) or 13.3(a)(ii);
      • indemnify, and upon demand reimburse, the Contractor for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register established by the PPSA or releasing any Materials charged thereby;
      • not register a financing change statement in respect of a security interest without the prior written consent of the Contractor;
      • not register, or permit to be registered, a financing statement or a financing change statement in relation to the Materials and/or collateral (account) in favour of a third party without the prior written consent of the Contractor;
      • immediately advise the Contractor of any material change in its business practices of selling the Materials which would result in a change in the nature of proceeds derived from such sales.
    • The Contractor and the Customer agree that sections 96, 115 and 125 of the PPSA do not apply to the security agreement created by these terms and conditions.
    • The Customer hereby waives its rights to receive notices under sections 95, 118, 121(4), 130, 132(3)(d) and 132(4) of the PPSA.
    • The Customer waives its rights as a grantor and/or a debtor under sections 142 and 143 of the PPSA.
    • Unless otherwise agreed to in writing by the Contractor, the Customer waives its right to receive a verification statement in accordance with section 157 of the PPSA.
    • The Customer shall unconditionally ratify any actions taken by the Contractor under clauses 3 to 13.5.
    • Subject to any express provisions to the contrary (including those contained in this clause 13),nothing in these terms and conditions is intended to have the effect of contracting out of any of the provisions of the PPSA.

14. Security and Charge
    • In consideration of the Contractor agreeing to supply the Materials and/or provide its Works and as acknowledged by the Contractor in accordance with any Acknowledgment Document the Customer grants the Contractor a security interest by way of a floating charge (registerable by the Contractor pursuant to the PPSA) over all of its present and after acquired rights, title and interest (whether joint or several) in all other assets that is now owned by the Customer or owned by the Customer in the future, including but not limited to those set out in any Acknowledgment Document, to the extent necessary to secure the repayment of monies owed under this Contract for provision of the Materials and/or Works under this Contract and/or permit the Contractor to appoint a receiver to the Customer in accordance with the Corporations Act 2001 (Cth).
    • The Customer indemnifies the Contractor from and against all the Contractor’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising the Contractor’s rights under this clause.
    • In the event that the Customer defaults or breaches any term of this Contract and as a result, the security provided in clauses 1,13.2and 14.1as applicable, is deemed insufficient by the Contractor to secure the repayment of monies owed by the Customer to the Contractor, the Customer hereby grants the Contractor a security interest as at the date of the default, by way of a charge, that enables the right and entitlement to lodge a caveat over any real property and or land owned by the Customer now, or owned by the Customer in the future, to secure the performance of the Customer of its obligations under these terms and conditions (including, but not limited to, the payment of any money), in accordance with the Acknowledgement Document.

15. Defects, Warranties and Returns, Competition and Consumer Act 2010 (CCA)
    • The Customer must inspect allMaterials on delivery (or the Works on completion) and must within forty-eight (48) hours of delivery notify the Contractor in writing of any evident defect/damage, shortage in quantity, or failure to comply with the description or quote. The Customer must notify any other alleged defect in the Materials/Works as soon as reasonably possible after any such defect becomes evident. Upon such notification the Customer must allow the Contractor to inspect the Materials or to review the Works provided.
    • Under applicable State, Territory and Commonwealth Law (including, without limitation the CCA), certain statutory implied guarantees and warranties (including, without limitation the statutory guarantees under the CCA) may be implied into these terms and conditions (Non-Excluded Guarantees).
    • The Contractor acknowledges that nothing in these terms and conditions purports to modify or exclude the Non-Excluded Guarantees.
    • Except as expressly set out in these terms and conditions or in respect of the Non-Excluded Guarantees, the Contractor makes no warranties or other representations under these terms and conditions including but not limited to the quality or suitability of the Materials/Works. The Contractor’s liability in respect of these warranties is limited to the fullest extent permitted by law.
    • If the Customer is a consumer within the meaning of the CCA, the Contractor’s liability is limited to the extent permitted by section 64A of Schedule 2.
    • If the Contractor is required to replace any Materials under this clause or the CCA, but is unable to do so, the Contractor may refund any money the Customer has paid for the Materials.
    • If the Contractor is required to rectify, re-supply, or pay the cost of re-supplying the Works under this clause or the CCA, but is unable to do so, then the Contractor may refund any money the Customer has paid for the Works but only to the extent that such refund shall take into account the value of Works and Materials which have been provided to the Customer which were not defective.
    • If the Customer is not a consumer within the meaning of the CCA, the Contractor’s liability for any defect or damage in the Materials is:
      • limited to the value of any express warranty or warranty card provided to the Customer by the Contractorat the Contractor’s sole discretion;
      • limited to any warranty to which the Contractor is entitled, if the Contractor did not manufacture the Materials;
      • otherwise negated absolutely.
    • Subject to this clause 15, returns will only be accepted provided that:
      • the Customer has complied with the provisions of clause 1; and
      • the Contractor has agreed that the Materials are defective; and
      • the Materials are returned within a reasonable time at the Customer’s cost (if that cost is not significant); and
      • the Materials are returned in as close a condition to that in which they were delivered as is possible.
    • Notwithstanding clauses 1 to 15.9 but subject to the CCA, the Contractor shall not be liable for any defect or damage which may be caused or partly caused by or arise as a result of:
      • the Customer failing to properly maintain or store any Materials;
      • the Customer using the Materials for any purpose other than that for which they were designed;
      • the Customer continuing to use any Materials after any defect became apparent or should have become apparent to a reasonably prudent operator or user;
      • interference with the Works by the Customer or any third party without the Contractor’s prior approval;
      • the Customer failing to follow any instructions or guidelines provided by the Contractor;
      • fair wear and tear, any accident, or act of God.
    • The Contractor may in its absolute discretion accept non-defective Materials for return in which casethe Contractor may require the Customer topay handling fees of up to thirty percent (30%) of the value of the returned Materials plus any freight costs.
    • Notwithstanding anything contained in this clause if the Contractor is required by a law to accept a return then the Contractor will only accept a return on the conditions imposed by that law.

16. Intellectual Property
    • Where the Contractor has designed, drawn, written plans or a schedule of Works, or created any products for the Customer, then the copyright in all such designs, drawings, documents, plans, schedules and products shall remain vested in the Contractor, and shall only be used by the Customer at the Contractor’s discretion. Under no circumstances may such designs, drawings and documents be used without the express written approval of the Contractor.
    • The Customer warrants that all designs, specifications or instructions given to the Contractor will not cause the Contractor to infringe any patent, registered design or trademark in the execution of the Customer’s order and the Customer agrees to indemnify the Contractor against any action taken by a third party against the Contractor in respect of any such infringement.
    • The Customer agrees that the Contractor may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, drawings, plans or products which the Contractor has created for the Customer.

17. Default and Consequences of Default
    • Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at the Contractor’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.
    • If the Customer owes the Contractor any money, the Customer shall indemnify the Contractor from and against all costs and disbursements:
      • incurred; and/or
      • which would be incurred and/or
      • for which by the Customer would be liable;

in regard to legal costs on a solicitor and own client basis incurred in exercising the Contractor’s rights under these terms and conditions, internal administration fees, the Contractor’s contract fees owing for breach of these terms and conditions’, including, but not limited to, contract default fees and/or recovery costs (if applicable), as well as bank dishonour fees.

• Further to any other rights or remedies the Contractor may have under this Contract, if a Customer has made payment to the Contractor, and the transaction is subsequently reversed, the Customer shall be liable for the amount of the reversed transaction, in addition to any further costs incurred by the Contractor under this clause 17 where it can be proven that such reversal is found to be illegal, fraudulent or in contravention to the Customer’s obligations under this Contract.
• Without prejudice to the Contractor’s other remedies at law the Contractor shall be entitled to cancel all or any part of any order of the Customer which remains unfulfilled and all amounts owing to the Contractor shall, whether or not due for payment, become immediately payable if:
  • any money payable to the Contractor becomes overdue, or in the Contractor’s opinion the Customer will be unable to make a payment when it falls due;
  • the Customer has exceeded any applicable credit limit provided by the Contractor;
  • the Customer becomes insolvent or bankrupt, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or
  • a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Customer or any asset of the Customer.

18. Cancellation
    • Without prejudice to any other remedies the parties may have, if at any time either party is in breach of any obligation (including those relating to payment) under these terms and conditions (“the Breaching Party”) the other party may suspend or terminate the supply or purchase of Materials and/or Works to the other party, with immediate effect, by providing the Breaching Party with written notice. Neither party will be liable for any loss or damage the other party suffers because one of the parties has exercised its rights under this clause.
    • If the Contractor, due to reasons beyond the Contractor’s reasonable control, is unable to deliver any Materials and/or Works to the Customer, the Contractor may cancel any Contract to which these terms and conditions apply or cancel Delivery of Materials and/or Works at any time before the Materials and/or Works are delivered by giving written notice to the Customer. On giving such notice, the Contractor shall repay to the Customer any money paid by the Customer for the Materials and/or Works. The Contractor shall not be liable for any loss or damage whatsoever arising from such cancellation.
    • The Customer may cancel delivery of the Materials and/or Works by written notice served within twenty-four (24) hours of placement of the order. If the Customer cancels delivery in accordance with this clause 3, the Customer will not be liable for the payment of any costs of the Contractor, except where a deposit is payable in accordance with clause 6.4. Failure by the Customer to otherwise accept delivery of the Materials and/or Works shall place the Customer in breach of this Contract.
    • Cancellation of orders for products made to the Customer’s specifications, or for non-stocklist items, will definitely not be accepted once production has commenced, or an order has been placed.

19. Privacy Policy
    • All emails, documents, images or other recorded information held or used by the Contractor is Personal Information, as defined and referred to in clause 3, and therefore considered Confidential Information. The Contractor acknowledges its obligation in relation to the handling, use, disclosure and processing of Personal Information pursuant to the Privacy Act 1988 (“the Act”) including the Part IIIC of the Act being Privacy Amendment (Notifiable Data Breaches) Act 2017 (NDB) and any statutory requirements, where relevant in a European Economic Area (“EEA”), under the EU Data Privacy Laws (including the General Data Protection Regulation “GDPR”) (collectively, “EU Data Privacy Laws”). The Contractor acknowledges that in the event it becomes aware of any data breaches and/or disclosure of the Customer’s Personal Information, held by the Contractor that may result in serious harm to the Customer, the Contractor will notify the Customer in accordance with the Act and/or the GDPR. Any release of such Personal Information must be in accordance with the Act and the GDPR (where relevant) and must be approved by the Customer by written consent, unless subject to an operation of law.
    • Notwithstanding clause 1, privacy limitations will extend to the Contractor in respect of Cookies where the Customer utilises the Contractor’s website to make enquiries. The Contractor agrees to display reference to such Cookies and/or similar tracking technologies, such as pixels and web beacons (if applicable), such technology allows the collection of Personal Information such as the Customer’s:
      • IP address, browser, email client type and other similar details;
      • tracking website usage and traffic; and
      • reports are available to the Contractor when the Contractor sends an email to the Customer, so the Contractor may collect and review that information (“collectively Personal Information”)

If the Customer consents to the Contractor’s use of Cookies on the Contractor’s website and later wishes to withdraw that consent, the Customer may manage and control the Contractor’s privacy controls via the Customer’s web browser, including removing Cookies by deleting them from the browser history when exiting the site.

• The Customer agrees for the Contractor to obtain from a credit reporting body (CRB) a credit report containing personal credit information (e.g. name, address, D.O.B, occupation, driver’s license details, electronic contact (email, Facebook or Twitter details), medical insurance details or next of kin and other contact information (where applicable), previous credit applications, credit history) about the Customer in relation to credit provided by the Contractor.
• The Customer agrees that the Contractor may exchange information about the Customer with those credit providers and with related body corporates for the following purposes:
  • to assess an application by the Customer; and/or
  • to notify other credit providers of a default by the Customer; and/or
  • to exchange information with other credit providers as to the status of this credit account, where the Customer is in default with other credit providers; and/or
  • to assess the creditworthiness of the Customer including the Customer’s repayment history in the preceding two (2) years.
• The Customer consents to the Contractor being given a consumer credit report to collect personal credit information relating to any overdue payment on commercial credit.
• The Customer agrees that personal credit information provided may be used and retained by the Contractor for the following purposes (and for other agreed purposes or required by):
  • the provision of Works; and/or
  • analysing, verifying and/or checking the Customer’s credit, payment and/or status in relation to the provision of Works; and/or
  • processing of any payment instructions, direct debit facilities and/or credit facilities requested by the Customer; and/or
  • enabling the collection of amounts outstanding in relation to the Works.
• The Contractor may give information about the Customer to a CRB for the following purposes:
  • to obtain a consumer credit report;
  • allow the CRB to create or maintain a credit information file about the Customer including credit history.
• The information given to the CRB may include:
  • Personal Information as outlined in 3above;
  • name of the credit provider and that the Contractor is a current credit provider to the Customer;
  • whether the credit provider is a licensee;
  • type of consumer credit;
  • details concerning the Customer’s application for credit or commercial credit (e.g. date of commencement/termination of the credit account and the amount requested);
  • advice of consumer credit defaults (provided the Contractor is a member of an approved OAIC External Disputes Resolution Scheme), overdue accounts, loan repayments or outstanding monies which are overdue by more than sixty (60) days and for which written notice for request of payment has been made and debt recovery action commenced or alternatively that the Customer no longer has any overdue accounts and the Contractor has been paid or otherwise discharged and all details surrounding that discharge(e.g. dates of payments);
  • information that, in the opinion of the Contractor, the Customer has committed a serious credit infringement;
  • advice that the amount of the Customer’s overdue payment is equal to or more than one hundred and fifty dollars ($150).
• The Customer shall have the right to request (by e-mail) from the Contractor:
  • a copy of the Personal Information about the Customer retained by the Contractor and the right to request that the Contractor correct any incorrect Personal Information; and
  • that the Contractor does not disclose any Personal Information about the Customer for the purpose of direct marketing.
• TheContractor will destroy Personal Information upon the Customer’s request (by e-mail) or if it is no longer required unless it is required in order to fulfil the obligations of this Contract or is required to be maintained and/or stored in accordance with the law.
• The Customer can make a privacy complaint by contacting the Contractorvia e-mail. The Contractor will respond to that complaint within seven (7) days of receipt and will take all reasonable steps to make a decision as to the complaint within thirty (30) days of receipt of the complaint. In the event that the Customer is not satisfied with the resolution provided, the Customer can make a complaint to the Information Commissioner at oaic.gov.au.

20. Building and Construction Industry Security of Payments Act 1999
    • At the Contractor’s sole discretion, if there are any disputes or claims for unpaid Materials and/or Works then the provisions of the Building and Construction Industry Security of Payments Act 1999 may apply.
    • Nothing in this Contract is intended to have the effect of contracting out of any applicable provisions of the Building and Construction Industry Security of Payments Act 1999 of New South Wales, except to the extent permitted by the Act where applicable.

21. Service of Notices
    • Any written notice given under this Contract shall be deemed to have been given and received:
      • by handing the notice to the other party, in person;
      • by leaving it at the address of the other party as stated in this Contract;
      • by sending it by registered post to the address of the other party as stated in this Contract;
      • if sent by facsimile transmission to the fax number of the other party as stated in this Contract (if any), on receipt of confirmation of the transmission;
      • if sent by email to the other party’s last known email address.
    • Any notice that is posted shall be deemed to have been served, unless the contrary is shown, at the time when by the ordinary course of post, the notice would have been delivered.

22. Trusts
    • If the Customer at any time upon or subsequent to entering in to the Contract is acting in the capacity of trustee of any trust or as an agent for a trust (“Trust”) then whether or not the Contractor may have notice of the Trust, the Customer covenants with the Contractor as follows:
      • the Contract extends to all rights of indemnity which the Customer now or subsequently may have against the Trust, the trustees and the trust fund;
      • the Customer has full and complete power and authority under the Trustor from the Trustees of the Trust as the case may be to enter into the Contract and the provisions of the Trust do not purport to exclude or take away the right of indemnity of the Customer against the Trust, the trustees and the trust fund. The Customer will not release the right of indemnity or commit any breach of trust or be a party to any other action which might prejudice that right of indemnity;
      • the Customer will not during the term of the Contract without consent in writing of the Contractor (the Contractor will not unreasonably withhold consent), cause, permit, or suffer to happen any of the following events:
        • the removal, replacement or retirement of the Customer as trustee of the Trust;
        • any alteration to or variation of the terms of the Trust;
        • any advancement or distribution of capital of the Trust; or
        • any resettlement of the trust fund or trust property.

23. General
    • Any dispute or difference arising as to the interpretation of these terms and conditions or as to any matter arising herein, shall be submitted to, and settled by, mediation before resorting to any external dispute resolution mechanisms (including arbitration or court proceedings) by notifying the other party in writing setting out the reason for the dispute. The parties shall share equally the mediator’s fees. Should mediation fail to resolve the dispute, the parties shall be free to pursue other dispute resolution avenues.
    • The failure by either party to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect that party’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable, that provision shall be severed from this Contract, and the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.
    • These terms and conditions and any Contract to which they apply shall be governed by the laws of New South Wales and are subject to the jurisdiction of the courts in that state. These terms prevail over all terms and conditions of the Customer (even if they form part of the Customer’s purchase order).
    • The Contractor may licence and/or assign all or any part of its rights and/or obligations under this Contract without the Customer’s consent provided the assignment does not cause detriment to the Customer.
    • The Customer cannot licence or assign without the written approval of the Contractor.
    • The Contractor may elect to subcontract out any part of the Works but shall not be relieved from any liability or obligation under this Contract by so doing. Furthermore, the Customer agrees and understands that they have no authority to give any instruction to any of the Contractor’s sub-contractors without the authority of the Contractor.
    • The Customer agrees that the Contractor may amend their general terms and conditions for subsequent future contracts with the Customer by disclosing such to the Customer in writing. These changes shall be deemed to take effect from the date on which the Customer accepts such changes, or otherwise at such time as the Customer makes a further request for the Contractor to provide Works to the Customer.
    • Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm, national or global pandemics and/or the implementation of regulation, directions, rules or measures being enforced by Governments or embargo, including but not limited to, any Government imposed boarder lockdowns (including, worldwide destination ports), etc, (“Force Majeure”) or other event beyond the reasonable control of either party. This clause does not apply to a failure by the Customer to make a payment to the Contractor, once the parties agree that the Force Majeure event has ceased.
    • Both parties warrant that they have the power to enter into this Contract and have obtained all necessary authorisations to allow them to do so, they are not insolvent and that this Contract creates binding and valid legal obligations on them.
    • The rights and obligations of the parties will not merge on completion of any transaction under this Contract, and they will survive the execution and delivery of any assignment or other document entered, for the purpose of, implementing any transaction under this Contract.
    • If part or all of any term of this Contract is or becomes invalid, illegal or unenforceable, it shall be severed from this Contract and shall not affect the validity and enforceability of the remaining terms of this Contract.